All services are subject to availability and may vary based on project scope, materials, and site conditions. Specific deliverables, timelines, and pricing will be outlined in a written project agreement or estimate provided before work begins.
3. Estimates & PricingWe offer free, no-obligation estimates to help you understand the scope and cost of your project. Estimates are based on the information provided during your consultation and our on-site assessment.
Please note that estimates are not final contracts. Final pricing will be confirmed in a written project agreement and may differ from the initial estimate if the scope of work, materials, or site conditions change. We are committed to transparent pricing with no hidden fees.
Important: Any changes or additions to the original scope of work requested after the project agreement is signed may result in additional costs and adjusted timelines. All change orders will be documented in writing and require your approval before proceeding.
4. Scheduling & AccessOnce a project agreement is signed and any required deposits are received, we will work with you to establish a project schedule. While we make every reasonable effort to meet projected timelines, unforeseen circumstances such as weather, supply chain delays, permitting issues, or discoveries during demolition may affect the schedule.
You agree to provide our team with reasonable access to the project site during agreed-upon working hours. If access is restricted or delayed for reasons within your control, timelines and costs may be adjusted accordingly.
5. Payment TermsPayment schedules, methods, and milestones will be outlined in your project agreement. Typical payment structures include a deposit upon signing, progress payments tied to project milestones, and a final payment upon completion and your walkthrough approval.
Late payments may result in work stoppage or project delays. Fedor Fabrication reserves the right to suspend work if payments are not received according to the agreed schedule. Any outstanding balances may be subject to interest or collection costs as permitted by Pennsylvania law.
6. Warranty & WorkmanshipWe stand behind the quality of our work. Fedor Fabrication provides a workmanship warranty on all labor performed, the specific terms and duration of which will be detailed in your project agreement.
This warranty does not cover damage caused by misuse, neglect, normal wear and tear, unauthorized modifications, or acts of nature. Manufacturer warranties on materials, fixtures, and appliances are separate from our workmanship warranty and are governed by the respective manufacturers’ terms.
To make a warranty claim, please contact us promptly at the information listed below. We will assess the issue and, if covered, schedule repairs at no additional cost to you.
7. Intellectual PropertyAll content on
fedorfab.com, including text, images, photographs, graphics, logos, and design elements, is the property of Fedor Fabrication or its licensors and is protected by copyright and other intellectual property laws.
You may not copy, reproduce, distribute, modify, or create derivative works from any content on this website without our prior written consent. Project photographs and design renderings remain the intellectual property of Fedor Fabrication unless otherwise agreed upon in writing.
8. Website UseYou agree to use
fedorfab.com only for lawful purposes. You may not use this website in any way that could damage, disable, or impair the site or interfere with any other party’s use of the site.
While we strive to keep all information on our website accurate and up to date, we do not guarantee the completeness or accuracy of any content, including pricing, service descriptions, or availability. Information on this site is provided for general reference only and does not constitute a binding offer or contract.
9. Communications & ConsentBy submitting a contact form, requesting an estimate, or providing your phone number or email address through our website, you consent to receive communications from Fedor Fabrication. These may include phone calls, emails, and text messages related to your inquiry, project, or our services.
Text messages may be sent to the phone number you provide. Message and data rates may apply. You can opt out of text messages at any time by texting STOP to
610-431-7150. Opting out of text messages will not affect other forms of communication related to an active project.
10. Limitation of LiabilityTo the fullest extent permitted by Pennsylvania law, Fedor Fabrication shall not be liable for any indirect, incidental, consequential, special, or punitive damages arising from or related to the use of this website or the performance of our services. This includes, without limitation, loss of profits, data, use, or goodwill.
Our total liability for any claim arising from our services shall not exceed the total amount paid by you under the applicable project agreement. Nothing in these terms excludes or limits liability that cannot be legally excluded or limited under applicable law.
11. IndemnificationYou agree to indemnify, defend, and hold harmless Fedor Fabrication, its owners, employees, contractors, and agents from and against any claims, damages, losses, liabilities, costs, and expenses (including reasonable attorney’s fees) arising from your breach of these terms, your misuse of the website, or any dispute between you and a third party related to our services.
12. TerminationEither party may terminate a project agreement in accordance with the cancellation and termination provisions outlined in that agreement. If no specific terms are stated, either party may terminate with written notice. You will be responsible for payment for all work completed and materials ordered or installed up to the date of termination.
We reserve the right to restrict or terminate your access to
fedorfab.com at our sole discretion if we believe you are violating these terms or using the site in an unauthorized manner.
13. Governing LawThese Terms of Service are governed by and construed in accordance with the laws of the Commonwealth of Pennsylvania, without regard to conflict of law principles. Any disputes arising under these terms shall be resolved in the courts of Chester County, Pennsylvania.
14. Changes to These TermsFedor Fabrication reserves the right to update or modify these Terms of Service at any time. Changes will be effective when posted on this page with an updated effective date. Your continued use of the website or services after changes are posted constitutes your acceptance of the revised terms.
We encourage you to review this page periodically to stay informed about the terms that apply to your use of our website and services.
15. Contact UsIf you have any questions about these Terms of Service, please reach out. We are happy to help.
